An arbitrator cannot act beyond the scope of reference and make findings on matters that have not been referred to arbitration.

Mr. S. K. Mahajan, J.

( 1 ) THE Arbitrator Mr. V. Nainani filed in Court this award made and published by him on 26th September, 1991 in the disputes between the parties referred to him under agreement No. 55/ee/pwd-19/da/ 88-89 relating to the work of construction of 100 bedded hospital in Khichripur, Delhi. Notice of filing of award was given to the parties and objections to the same have been filed by the respondent-Union of India.

( 2 ) IN its objections petition under Sections 30 and 33 of the Arbitration Act, it has been alleged that the award passed by the Arbitrator is arbitrary, illegal and against facts and law and was beyond the scope of reference. It is alleged that the Arbitrator misconducted himself by saying that the Union of India had not reserved its right to claim damages for delay in the completion of the work and the work had not been taken up at the risk and cost of the contractor till the date of the award and as such, according to the Arbitrator, the risk action failed. It is also alleged in the objection petition that the Arbitrator has wrongly decided claim No. 2 stating that the respondent impliedly accepted the performance of the claimant beyond the stipulated date of completion and, according to the Objector, arbitrarily awarded 75 per cent of the escalation beyond the stipulated period of contract. This finding of the Arbitrator, according to the Objector, is beyond the terms of reference and beyond his jurisdiction. The award on future interest and the cost of escalation have also been challenged by the Objector. Reply to the objections had been filed and on the pleadings of the parties, following issues were framed :- 1. Whether the award is liable to be set aside for the reasons stated in the objections filed by the respondent? 2. Relief. I have heard learned Counsel for the parties.

( 3 ) THE main objection to the award by the Union of India is that the Arbitrator has acted beyond the scope of reference inasmuch as the question whether the Union of India had or could execute the balance work at the risk and cost of the contractor had not been referred to arbitration and by giving the finding that as on the date of giving the award. Union of India had not taken up the work at the risk and cost of the contractor and had not reserved to itself the right to claim damages for delay in completion of work and as such risk action failed, was beyond the scope of reference of the Arbitrator. The argument is that by giving this finding the Arbitrator has for all intents and purposes barred the Union of India from claiming any amount by way of damages from the contractor for the work which is being executed at the risk and cost of the contractor. It is, therefore, submitted that the Arbitrator could not have given this finding. On the question of award of a sum of Rs. 92,621 against claim of the contractor on account of increase in rates, the argument is that the Arbitrator could not have awarded this amount because the contractor had already been paid for the escalation of the rates.

( 4 ) AFTER going through the record and after hearing the Counsel for the parties, I find that there is force in the argument of the Counsel for Union of India that there was no occasion for the Arbitrator to give any finding on the question whether risk action had failed or not because that was not a question which had been referred to the Arbitrator. The Arbitrator has given these findings in the preamble of the award discussing claim Nos. 1 to 4, this question had not been argued nor there was any occasion for the Arbitrator to discuss this question of risk cost, as it was not referred to him. It appears that the Arbitrator has given his finding out of context. Mr. Kumar appearing for the contractor has not been able to support the finding of the Arbitrator on this point. I, therefore, set aside this part of the findings of the Arbitrator.

( 5 ) FIND that the Arbitrator on considering the material on record has given his

Click Here to Read the rest of this document