O R D E R

The petitioner/employer awarded a contract to the respondent/

contractor for the construction of quarters for cadets at Chennai. For ease of reference, the petitioner is referred to as the employer and the respondent as the contractor throughout this order. The total value of the contract was Rs.13,99,28,741.41. Work was to be executed in two phases: Phase-I to be completed by 22.01.2009 and Phase-II by 22.04.2010. In course of execution of Phase-I work, extensions of time were requested for and granted. By communication dated 07.09.2009, the employer informed the contractor that Phase-I work had been satisfactorily completed on 05.09.2009 subject to the rectification of defects listed in Appendix-A to said communication. The formal extension order for extension up to 05.09.2009 was issued by the employer on 16.04.2010 under condition 11 (A)(vii) of IAFW-2249, General Conditions of Contract (the GCC). Similarly, in course of execution of Phase- II work, extensions of time were requested for and granted. The last extension that was granted while work was being carried on was up to 31.03.2012. All extensions were under condition 11 (A)(vii) of the GCC. Thereafter, by communication of 07.07.2012, the employer informed the contractor that work was completed on 05.07.2012 subject to rectification of the defects listed in Appendix A and B of said communication.

2. By communication dated 13.04.2015, the contractor invoked the arbitration clause in the contract and requested the employer to take necessary steps to form the arbitral tribunal to adjudicate 31 claims. As is evident from the narration in the preceding paragraph, while work was carried out and completed subject to defect rectification on 05.07.2012, extension of time for the period running from 01.04.2012 to 05.07.2012 had not been granted. Therefore, parties corresponded on said issue and the processing of the final bill. In that context, a letter dated 07.01.2016 and a letter dated 18.02.2016 enclosing an affidavit were issued by the contractor agreeing to withdraw all court cases and the request for appointment of an arbitrator. Pursuant thereto, as requested, extension of time was granted up to 05.07.2012. Meanwhile, pursuant to a communication dated 16.06.2016 from the Engineer-in-chief, the arbitrator entered upon reference and called upon parties to submit pleadings by notice dated 02.07.2016. In response, by letter dated 16.07.2016, the employer informed the arbitrator about the submission of an affidavit by the contractor agreeing to withdraw the request for arbitration, and the grant of extension of time pursuant thereto. Therefore, it was submitted that there are no claims/disputes requiring adjudication.

3. Thereafter, by communication dated 08.08.2016, the contractor informed the Arbitral Tribunal that the affidavit was given under pressure since the contractor was informed that extension of time would be granted only if such affidavit is provided, and that the final bill would be paid subject to such condition. An application under Section 16 of the Arbitration and Conciliation Act, 1996 (the Arbitration Act) was filed by the employer in these facts and circumstances on 06.09.2016. By order dated 04.11.2016, the Arbitral Tribunal rejected the jurisdictional challenge on the ground that the letter dated 07.01.2016 and affidavit were not submitted under free consent. The arbitral proceedings continued and the contractor herein made 16 claims before the Arbitral Tribunal.

4. Claims 1 to 11 and 16 were claims for reimbursement of costs incurred in relation to work executed. Claim 12 pertained to amounts due and payable under the final bill. Claim 13 was for release of fixed deposits. Claim 14 was for interest and Claim 15 for costs. The employer made five counter claims in respect of the following: differential cost incurred by engaging a third party contractor (risk and cost claim); compensation for delay in completion of work; loss of reputation; non-su