CAPITAL GREENS FLAT BUYER ASSOCIATEION vs DLF UNIVERSAL LIMITED

Judicial Analysis Court Copy Headnote Facts Arguments Court observation

2020 Supreme(Online)(NCDRC) 16

NATIONAL CONSUMER DISPUTES REDRESSAL COMMISSION
V.K. JAIN, J
CAPITAL GREENS FLAT BUYER ASSOCIATEION – Appellant
Versus
DLF UNIVERSAL LIMITED – Respondent

Advocates:
For the Appellants/Petitioners:Mr. Anil Sapra, Sr. Advocate, Mr. Ajay Kohli, Advocate, Mr. Sarthak Katyal, Advocate, Ms. Astha Garg, Advocate, Ms. Medha Rai, Advocate, Mr. Amit Joshi, Advocate, Ms. Prabhat Kaur, Advocate, Mr. B.P. Agarwal, Advocate (CC/1751/2016), Mr. Ashish Verma, Advocate, Mr. Varun Chopra, Advocate, Mr. Jitendra Malkan, Advocate, Mr. Vishal Bhatnagar, Advocate, Mr. Dhiraj Madan, Advocate (CC/2640/2017) and (CC/3619/2017), Mr. S.K. Pal, Advocate, Mr. Sunil Mund, Advocate, Mr. Amit Kumar, Advocate, Mr. Soumya Patra, Advocate, Mr. Aditya Parolia, Advocate (CC/3441/2017), Mr. Nithin Chandra, Advocate, Ms. Harshita Chauhan, Advocate, Mr. Akash Khurana, Advocate
For the Respondents:Mr. Pinaki Misra, Sr. Advocate, Mr. Pravin Bahadur, Advocate, Mr. Kartik Nayar, Advocate, Ms. Seema Sundd, Advocate, Mr. Ritu Raj Srivastava, Advocate, Mr. Kamal Taneja, Advocate, Mr. Aditya P.N. Singh, Advocate, Mr. Snehil Srivastava, Advocate

Table of Content
1. overview of consumer complaints and defendants. (Para 1 , 2 , 3 , 4)
2. nature of complaints and the society's registration. (Para 5 , 6 , 7 , 8 , 9)
3. understanding of the 'super area' in the agreements. (Para 12 , 13 , 14 , 15)
4. definitions and implications of club and parking charges. (Para 16 , 17 , 18 , 19 , 20)
5. examination of force majeure claims and delays. (Para 21 , 22 , 23)
6. developer's liability regarding possession delays. (Para 24 , 25 , 26 , 27 , 28)
7. determining compensation for delayed possession. (Para 31 , 32 , 33 , 34)
8. final orders for compensation and liabilities. (Para 35 , 36 , 37)

ORDER

JUSTICE V.K. JAIN, PRESIDING MEMBER

The opposite party namely DLF Universal Limited (hereinafter referred to as “Developer”) is the developer of the large residential project namely “DLF Capital Greens” developed on the land situated at Shivaji Marg, Moti Nagar, New Delhi. 2870 residential apartments in 23 residential towers have been constructed by the developer in three phases, the first and second phase comprising of 10 towers each and the third phase comprising of three towers. Laresen & Toubro was appointed as the Principal Contractor for constructin

Click Here to Read the rest of this document

2020 Supreme(Online)(NCDRC) 16

NATIONAL CONSUMER DISPUTES REDRESSAL COMMISSIONV.K. JAIN, JCAPITAL GREENS FLAT BUYER ASSOCIATEION – AppellantVersusDLF UNIVERSAL LIMITED – Respondent

NATIONAL CONSUMER DISPUTES REDRESSAL COMMISSION
V.K. JAIN, J
CAPITAL GREENS FLAT BUYER ASSOCIATEION – Appellant
Versus
DLF UNIVERSAL LIMITED – Respondent