Back
HIGH COURT MALAYA IPOH
KERAJAAN MALAYSIA – Appellant
Versus
VEN-COAL RESOURCES SDN BHD – Respondent
| Table of Content |
|---|
| 1. contract awarded for building construction. (Para 1 , 1) |
| 2. delays caused by headmaster and unforeseen factors. (Para 2 , 8) |
| 3. piling work complications due to additional depths. (Para 3 , 21 , 22) |
| 4. request for extension of time (eot) denied. (Para 4 , 5 , 6) |
| 5. contract award and project delays. (Para 7) |
| 6. eot granted generally due to price increases. (Para 10 , 11 , 12) |
| 7. request for eot must consider prior extensions and reasons. (Para 13 , 16 , 19 , 38) |
| 8. stalemate due to headmaster's requirements. (Para 14 , 15) |
| 9. concurrent delays and extension evaluations. (Para 18 , 23) |
| 10. termination of contract evaluations. (Para 29 , 35) |
| 11. termination based on lack of diligent progress is contentious. (Para 30 , 31 , 32) |
| 12. counterclaim for payments arising from wrongful termination. (Para 56 , 57 , 58 , 59) |
[1] The plaintiff awarded to the defendant a contract to construct and complete 2 additional blocks of building for a school called Sekolah Kebangsaan Sungai Baharu, Kuala Kerian, Daerah Kuala Kerian, Perak ("the Project"). The contract entered into was the Standard Form PWD 203 (Rev. 10/83) Contract. The contract sum was for RM3,511,597.00. Under the contract the c
An indispensable Tool for Legal Professionals, Endorsed by Various High Court and Judicial Officers
Please visit our Training & Support
Center or Contact Us for assistance
Scan Me!
India’s Legal research and Law Firm App, Download now!
For Daily Legal Updates, Join us on :
Back to top
