Ashutosh Kumar, J.—Heard Mr. P.N. Shahi, learned senior Advocate for the petitioner and Mr. Upendra Pratap Singh for the State.

2. The petitioner, a proprietorship firm, through its proprietor, has approached this Court against the order dated 06.04.2021 passed by the Executive Engineer, PHED, Bettiah whereby the petitioner has been debarred for an indeterminate period from entering into any agreement with any department of the Government.

3. Mr. Shahi, while assailing the order, lays primary emphasis on the debarment for limitless period which is not in tune with the law relating to blacklisting and debarment.

4. The petitioner was selected as a concessionaire by the PHED, West Champaran, for carrying out the 13 projects of Single Gram Panchayat/Habitation Piped Water Supply Schemes (SGS/SHS) in West Champaran in the district of Bihar at a contract price of Rs. 441.90 lacs.

5. It has been urged on behalf of the petitioner that though the Joint Director, State Project Management Unit, gave green signal to the petitioner to proceed with the work at one place for it to be finished within a period of 11 months but, the selected site was found to be completely water-logged and in a low-lying area where tube-well/ boring work could not have been carried out.

This was promptly reported to the department.

6. Though a survey and search for a new site was undertaken but, the site was changed only after a delay of four months, which was one of the major reasons for non-completion of the project in time. Shortly thereafter, national lock-down was imposed in view of the outbreak of Covid-19 Pandemic which continued from 25.03.2020 to 17.05.2020. This necessitated an extension of time for the petitioner to complete the work which was, though, sought by the petitioner but the department, for no good reason, delayed the grant of execution. The work therefore could not be started before the extension of time. Only on 17.02.2021, an extension of time was given to the petitioner but that was only for 33 days, which reflected complete non-application of mind. When the work of the project had not even effectively begun, extending the time period by 33 days, Mr. Shahi argues, was very unreasonable and perhaps, activated by malicious intent to any how prevent the petitioner from completing the project for the department to terminate the contract.

7. On notice to the petitioner for not having completed the contract of time for future action of debarment, the petitioner replied to the same, detailing the above noted circumstances, but by order dated 06.04.2021, the petitioner was debarred, as noted above, for a indeterminate period from entering into any contract with any department of the Government.

8. Surprisingly, the order reflects that the extension till 17.02.2021 was given without any liquidated damages but, after the order of debarment was passed, there was a further conditional extension of one year, subject to payment of liquidated damages of 44.19 lacs.

9. The petitioner seeks to assail the aforenoted decision viz. indeterminate debarment with all government departments and extension of time which also appears to have been consumed by now but, only with liquidated damages of Rs. 44.19 lacs.

10. The grounds of assail are primarily the limitless debarment and not adverting to the reasonable and plausible explanation offered by the petitioner for delayed execution of project.

11. The learned counsel for the petitioner therefore submits that the order of debarment ought to be quashed, an opportunity be given to the petitioner to explain his cause afresh and a direction be issued to the department to refer to the reply and then take a fresh decision with respect to further extension with or without liquidated damages and making available new sites for carrying out the rest of the project.

12. It has also been pointed out by the learned counsel for the petitioner that almost 90% of the work, despite such handicaps, has been done for which payments have als