Parties to a joint venture must fulfill contractual obligations or risk liability, while implied consent to delays does not absolve breach of contract responsibilities.

[1] This case presents a classic intersection of contractual obligations, commercial reliance, and the consequences of non-performance in a high-stakes joint venture development. As emerged at trial, this dispute is not merely about delayed approvals and missed deadlines but about the expectations and responsibilities of parties engaged in a sophisticated land development agreement.

[2] The Plaintiff asserts its right to claim contractual entitlements under their Joint Venture Agreement for land development dated 10 November 2014 (JVA). The 1st defendant and its guarantors (the 2nd defendant and one Lai Hoong Sung (the Deceased) with now the 3rd and 4th defendants cited in this suit as they are the co-administrators of the Deceased's estate) argue that the contract should be deemed terminated due to unfulfilled conditions precedent, raising critical questions about waiver, extensions by conduct, and liability.

Agreed Facts

[3] The following facts were agreed upon by all the parties and remain undisputed:

(a) The JVA between the Plaintiff and the 1st defendant that they had executed on 10 November 2014 is for a residential development project on land held by the Plaintiff under HS(M) 26010, Lot PT 40200 and HS(M) 26533, Lot PT 40593.

(b) The 1st defendant had made a deposit payment of RM200,000.00 as per cl 3 of the JVA to the Plaintiff. The payment by the 1st defendant was made in two tranches (RM30,000.00 and RM170,000.00).

(c) The 1st defendant had successfully amalgamated the two pieces of land for development and subdivided the development land into 16 individual lots.

(d) The 2nd defendant and the Deceased executed a Guarantee and Indemnity Agreement on the same date as the JVA — 10 November 2014 (the Guarantee) whereby they had jointly and severally undertook and guaranteed the 1st defendant's obligations under the JVA including the payment of RM2,425,000.00 (the total after deducting the deposit payment of RM200,000.00) with interest at 8% per annum from the agreed completion date of 10 May 2018 until full settlement.

(e) The 2nd defendant and the Deceased were directors of the 1st defendant at the material times and through cl 2(f) of the Guarantee, it was agreed that their obligations will continue to exist until released through the implementation of the Guarantee, regardless of any resignation as director, unless the Plaintiff agrees in writing to substitute the director who resigned.

(f) The Plaintiff had not, at any time, given consent to replace any of the guarantors under the Guarantee.

(g) The 2nd defendant and the Deceased agreed that their liability under the Guarantee shall not in any way be relieved, diminished or affected by death, their insanity or any incapacity (cl 2(1) of the Guarantee).

(h) The Plaintiff's cause of action under the Guarantee continues to exist against the estate of the Deceased based on the provisions of the Guarantee and in accordance with s 8(1) of the Civil Law Act 1956 .

(i) This action by the Plaintiff is commenced against the 3rd and 4th defendants as personal representatives for the estate of the Deceased according to O 15 r 6A of the Rules of Court 2012 (RoC).

Evidence Adduced At Trial

[4] At trial, the Plaintiff called upon its representative (PW1), who gave evidence on the Plaintiff's entitlement under the JVA and the 1st defendant's failure to perform its contractual obligations. PW1 testified that the Plaintiff had contributed the lands for