SupremeToday Landscape Ad
Back
Next
Judicial Analysis Court Copy Headnote Facts Arguments Court observation
Listen Audio Icon Pause Audio Icon
judgment-img

1997 Supreme(AP) 468

Andhra Pradesh High Court
Judges : A.HANUMANTHU
State Of A.P., rep.by Superintending Engineer - Appellant
Versus
K.Bapiraju - Respondent
Decided On : 06-10-97

Headnote:

Contract Act - Section 55 - Working Contract - As per terms and conditions of contract work had to be completed within six months from date of handing over site to contractor - Completion of work was delayed beyond period fixed in contract - For this contractor had attributed delay on part of department for not handing over uninterrupted possession of whole site to him - Thus dispute arose between contractor and department - As per terms of contract any dispute arising out of above contract has to be referred to panel of arbitrators - Contractor filed an arbitration petition before panel of arbitrators as provided under contract referring dispute for their decision - Hence learned judge made award as rule of Court - But as regards interest it was observed that interest for period between date of arbitrator entering upon reference and till date of award has to be deleted as it relates to pendente lite interest - Held, While seeking extension of time for completing work till through his letter addressed to Chief Engineer contractor did not reserve any right to claim any compensation for any loss occasioned to him for delay in making available site for completing work - Therefore is squarely attracted as held by this Court in above mentioned cases - Though there is no specific reference in pleadings or in grounds of objections relevant facts give rise to application - It is bounden duty of sole arbitrator to pass award in accordance with law statutory provision contained - For this reason also it has to be held that arbitrator has committed legal misconduct in accepting claim though partly - It is not disputed that there is provision in deviation statements prepared by department for excavation of key trenches and it is only on instructions from department contractor could have excavated key trenches worth - Petition are partly allowed.

A. HANUMANTHU, J.

( 1 ) THESE two matters are directed against the common order dated 22-3-1991 of the II Additional Judge, City Civil Court, Hyderabad passed in O. S. No. 1096 of 1987 and O. P. No. 528 of 1987 and they are also being disposed of by a common order.

( 2 ) THE State of Andhra Pradesh represented by the Superintending engineer, N. S. Canal Circle, Nuzvid and the Executive Engineer, N. S. Left canal, Nuzvid Milavaram are the appellants/petitioners in both the matters and the contractor K. Bapiraju and the sole arbitrator Mohd. Karimullah Khan are the respondents.

( 3 ) THE facts leading for preferring this appeal and revision are, in brief, as follows: the Superintending Engineer, N. S. Left Canal Circle, Nuzvid had invited tenders for "excavation of Machavarm major" from K. M. 6 to K. M. 8. The first respondent herein, K. Bapiraju, contractor, had submitted his tender for that work at Rs. 4,04,759 with 7. 52% excess over the estimated contract value of rs. 3,76,431/ -. The Superintending Engineer accepted the said tender of the contractor and agreement was executed on 29-7-1978. As per the terms and conditions of the contract, the work had to be completed within six months from the date of handing over the site to the contractor. The completion of the work was delayed beyond the period fixed in the contract. For this the contractor had attributed the delay on the part of the department for not handing over uninterrupted possession of the whole site to him on 10-7-1978. Thus the dispute arose between the contractor and the department. As per the terms of the contract, any dispute arising out of the above contract has to be referred to the panel of the arbitrators. The contractor filed an arbitration petition dated 31-5-1983 before the panel of arbitrators as provided under the contract referring the dispute for their decision. The panel arbitrators passed an award on 9-2-1984. Having been aggrieved with the award, the contractor filed the suit O. S. No. 247/84 and O. P. No. 262/84 on the file of II Additional judge, City Civil Court, Hyderabad. The learned judge by his judgment dated 29-8-1986 set aside the award dated 9-2-1984 passed by the panel arbitrators and appointed the second respondent, herein, Mohd. Karimullah Khan, Chief engineer as the sole arbitrator to decide the dispute between the parties. In pursuance of the said order, the second respondent/sole arbitrator entered upon the reference and passed the award on 15-6-1987. As there was some mistake in the heading of the claim for Rs. 30,000/-, the second respondent- arbitrator has given correction on 24-8-1987. The arbitrator allowed the claim nos. 1 and 5 to 8 and rejected the claim Nos. 2 to 4. The arbitrator also awarded interest at 24% per annum with effect from 31-5-1983 i. e. , the date on which the first claim petition was filed before the arbitrators till the date of payment. In so far as the claim Nos. 1 and 5 to 8 the contractor filed the suit O. S. No. 1096/87 on the file of the II Additional Judge, City Civil Court, Hyderabad for making the award rule of the Court. The State Government preferred o. P. No. 528/87 on the file of the II Additional Judge, City Civil Court, hyderabad to set aside the award in respect of the claim No. 1 and 5 to 8 and granting of interest. Both the matters were tried together. No oral evidence was adduced on either side. But Exs. A-1 to A-5 were marked on behalf of the contractor and Ex. B-1 was marked on behalf of the Superintending engineer. Exs. C-1 to C-3 were also marked. On consideration of the evidence on record, the learned II Additional Judge held that there was no misconduct on the part of the arbitrator and that the arbitrator has given cogent and convincing reasons for his conclusions in passing the award. Hence the learned judge made the award as rule of the Court. But as regards the interest, it was observed that the interest for the period between the date of arbitrator entering upon the reference a




































Click Here to Read the rest of this document
1
2
3
4
5
6
7
8
9
10
11
SupremeToday Portrait Ad
supreme today icon
whatsapp-icon Back to top