JUDGMENT

1. This revision under section 19 of the Madhya Pradesh Madhyastham Adhikaran Adhiniyam, 1983 (hereinafter referred to as Act of 1983) takes exception to award dated 3.5.2002, passed by Madhya Pradesh Arbitration Tribunal, Bhopal, in reference Case No.48/1991, allowing the counter claim of the respondent.

2. Brief facts for adjudication of the present revision are that Item Rate Tender of the applicant for the work of providing Cement Concrete Lining in Bansagar, Common Water Carrier (CWC) from K. 16.00 to 16.50 Km. was accepted by the respondent vide letter dated 26.12.1983. The work-order was issued to the applicant on 30.1.1984. The cost of work was Rs.20.50 lacs.

3. According to the applicant, after the issuance of work-order, he mobilized the machinery and deployed local and outside labourers on the site. Inspite of making all preliminary arrangements for starting the work, the department failed to perform its contractual obligations and commitments in time, resulting in avoidable delay which has caused immense loss to him in terms of escalation in prices and loosing of opportunity to get some other work etc. The applicant stated that despite herculean efforts to complete the work, there was no proper redressal of his grievances under those circumstances, he had to withdraw from the site on 31.3.1990. He stated that on 7.8.1989, he submitted the quantified claims before the Superintendent Engineer. Since no response was received, the revised claims was submitted vide letter dated 4.2.1991 before the said authority. His total claims was for Rs.4,02,136/- under various heads. Since the same also did not evoke any response from the respondent, therefore, the applicant approached the Madhya Pradesh Tribunal under section 7 of the Act, 1983.

4. The respondents in their reply to the petition have denied the claims of the applicant. According to respondents, the delay was due to failure and breaches on the part of the applicant, hence, the respondents could not be held responsible for any loss allegedly suffered by the contractor on that account. The applicant lacked sufficient resources to carry out the work. The applicant had five contracts in hand in the relevant period and, therefore, it had become unmanageable for the applicant to carry out all the works as per the construction programme. The respondents submitted their counter claim of Rs.2,38,602/- under various heads.

5. The learned Arbitral Tribunal allowed both the parties to prove the claim and counter claim. On the basis of material available on record, all the claims raised by the applicant were rejected except the one of earnest money and security deposit which was of Rs.16,179/-. The learned Arbitral Tribunal, however, allowed the counter claim of Rs.2,69,908/- with certain adjustment. It is this part of the impugned award of allowing counter claim is under challenge at the instance of the applicant in the present proceedings.

6. We have heard learned counsel appearing for the parties and perused the record.

7. Learned counsel for the applicant has placed reliance on the decision of the Full Bench of this Court in the matter of Ravikant Bansal, Engineers and Contractors v. Madhya Pradesh Audyogik Vikas Nigam Gwalior [2006(2) JLJ 186 = 2006(2) MPLJ 299] and the decision in the matter of Dr. Surendranath Reddy v. State of Madhya Pradesh [Civil Revision No.1973/2000, order dated 21.09.2015] . According to him the Arbitral Tribunal has erred in allowing the counter claim of the respondents. Unless the dispute is first referred to the final authority in terms of the works contract, the counter claim was not maintainable. He states that the Tribunal should only entertain a counter claim preferred by the opposite party, when the same is first referred to the final authority for final decision under the terms of the contract. No other point is argued/pressed by the learned counsel for the applicant.

8. Learned counsel appearing for the respondent/State supported the im